Home Improvement Contract – California
This product states who the contract is between date the contract was signed, location of the contractor, contract price, licensing, approximate start date, approximate completion date, drawings, specifications, and permits, property lines, access to work, financing, standard materials, nonstandard materials, hazardous materials, work allowance and conflict, mechanics’ Lien warning, change orders and amendments, preparations and work, plumbing, electrical service, plaster, filled ground, termite work, removal of material, extra time, damage to project and insurance, commercial general liability insurance, workers compensation insurance, protection of owner’s property, guarantee of materials and workmanship, work stoppage, completion and occupancy, notice, integration clause, corrective or repair work, arbitration of disputes, attorneys’ fees, and information about the contractors’ state license board.
Remodeling Contract – Legal Document
This product states who the contract is between, date the contract was signed, the contractor’s address, project address, contract price, licensing, approximate start date, approximate completion date, drawings and permits, property lines, access to work, financing, standard materials, nonstandard materials, hazardous materials, work allowance and conflict, mechanics’ lien warning, change orders and amendments, preparation and work, extra work and changes, plumbing, electrical service, plaster, filled ground or rock, termite work, removal of material and debris, extra time, damage to project and insurance, commercial general liability insurance, workers compensation insurance, protections of owner’s property, guarantee of materials and workmanship, work stoppage, completion and occupancy, notice, integration clause, corrective or repair work, arbitration of disputes, attorneys’ fees, and information about contractors’ state license board.
Application for Conditional Absolute Underground Water Right
Groundwater can either be privately owned or publicly owned. Groundwater owned by the State is usually distributed through an appropriation system. Privately owned groundwater may allow unlimited production or limited production rights based on land ownership or liability rules.
Water beneath the surface can essentially be divided into three zones: 1) the soil water zone, or vadose zone, 2) an intermediate zone, or capillary fringe, and 3) the ground water, or saturated zone.
The depth of the groundwater supply may dictate how, and if, you can drive or drill your well. For good potable water, you will have to go deep enough. Acceptable water will usually require going at least 30 feet down, but better water will usually be even deeper. Never drive or drill a well in a marshy, wet area.
Water rights are a type of interest that may attach to real estate ownership and pertain to the rights to use adjacent bodies of water. Different types of waters rights exist based on various forms of water that border or exist on a property.
Motion In Limine To Exclude Unreliable Statements
Motion to exclude and restrict statements during trial based on their degree of reliability and credibility.
Â
Complaint and summons for Assault and premise Liability
Complaint, summons and civil cover sheet for a case filed in Colorado against a bar and their bouncer for beating up a patron.
Plaintiff’s First Amended Draft Jury Instructions and Verdict Forms
PLAIINTIFF’S FIRST AMENDED DRAFT JURY INSTRUCTIONS AND VERDICT FORMS Negligence, COMPARATIVE NEGLIGENCE OF PLAINTIFF — SINGLE DEFENDANT — NO DESIGNATED NONPARTY INVOLVED, NEGLIGENT MISREPRESENTATION CAUSING FINANCIAL LOSS IN A BUSINESS TRANSACTION — ELEMENTS OF LIABILITY, BREACH OF EXPRESS WARRANTY UNDER U.C.C. — ELEMENTS OF LIABILITY
Premise liability and assault Complaint
Complaint against bar owner for failure to provide a safe environment for patron as well as complaint against unknown person who assaulted client
Complaint for Product Liability – Georgia
Product Liability complaint and failure to warn
Amended Complaint for Premise Liability – Missouri
A lawsuit filed for premise liability, complaint
Auto accident complaint with Vicarious Liability
A auto accident complaint filed in Federal District court based on Diversity